HomeMy WebLinkAbout20101216Application.pdfeslDA~POR~
An IDACORP Company
DONOVAN E. WALKER
Senior Counsel
dwalkercæidahopower.com
December 16,2010
VIA HAND DELIVERY
Jean D. Jewell, Secretary
Idaho Public Utilties Commission
472 West Washington Street
P.O. Box 83720
Boise, Idaho 83720-0074
Re: Case No. IPC-E-10-52
IN THE MATTER OF THE APPLICATION OF IDAHO POWER COMPANY
FOR A DETERMINATION REGARDING THE FIRM ENERGY SALES
AGREEMENT FOR THE SALE AND PURCHASE OF ELECTRIC ENERGY
BETWEEN IDAHO POWER COMPANY AND BRAVO WIND LLC
Dear Ms. Jewell:
Enclosed for filing please find an original and seven (7) copies of Idaho Power
Company's Application in the above matter.
Iy yours,f t(rJ
Donovan E. Walker
DEW:csb
Enclosures
1221 W. Idaho St. (83702)
P.O. Box 70
Boise. ID 83707
DONOVAN E. WALKER (ISB No. 5921)
LISA D. NORDSTROM (ISB No. 5733)
Idaho Power Company
P.O. Box 70
Boise, Idaho 83707
Telephone: (208) 388-5317
Facsimile: (208) 388-6936
dwalkerayidahopower.com
Inordstrom((idahopower.com
RECEl
'Hunnrr. i" PY3.' "'9luiU Uk.. b n . J
Attorneys for Idaho Power Company
Street Address for Express Mail:
1221 West Idaho Street
Boise, Idaho 83702
BEFORE THE IDAHO PUBLIC UTILITIES COMMISSION
IN THE MA TIER OF THE APPLICATION )
OF IDAHO POWER COMPANY FOR ) CASE NO. IPC-E-10-52
A DETERMINATION REGARDING THE )
FIRM ENERGY SALES AGREEMENT FOR ) APPLICATION
THE SALE AND PURCHASE OF ELECTRIC )
ENERGY BETWEEN IDAHO POWER )
COMPANY AND BRAVO WIND LLC. )
)
Idaho Power Company ("Idaho Powet' or "Company"), in accordance with RP 52
and the applicable provisions of the Public Utilty Regulatory Policies Act of 1978
("PURPA"), hereby respectfully applies to the Idaho Public Utilties Commission ("I PUC"
or "Commission") for an Order accepting or rejecting the Firm Energy Sales Agreement
("FESA") between Idaho Power and Bravo Wind LLC ("Bravo" or "Sellet') under which
Bravo would sell and Idaho Power would purchase electric energy generated by the
Bravo Wind ("Facilty") located near Burley, Idaho.
APPLICATION - 1
In support of this Application Idaho Power represents as follows:
i. BACKGROUND
1. Sections 201 and 210 of PURPA, and pertinent regulations of the Federal
Energy Regulatory Commission ("FERC"), require that regulated electric utilities
purchase power produced by cogenerators or small power producers that obtain
qualifying facilty ("OF") status. The rate a OF receives for the sale of its power is
generally referred to as the "avoided cost" rate and is to reflect the incremental cost to
an electric utilty of electric energy or capacity or both, which, but for the purchase from
the OF, such utilty would generate itself or purchase from another source. The
Commission has authority under PURPA Sections 201 and 210 and the implementing
regulations of the FERC, 18 C.F.R. § 292, to set avoided costs, to order electric utilties
to enter into fixed-term obligations for the purchase of energy from OFs, and to
implement FERC rules.
2. Bravo proposes to design, construct, install, own, operate, and maintain a
29.9 megawatt ("MW") (Maximum Capacity Amount) wind generating facilty to be
located near Burley, Idaho. The Facilty wil be a OF under the applicable provisions of
PURPA. The FESA for this Facilty, as well as the FESAs for Alpha Wind LLC, Charlie
Wind LLC, Delta Wind LLC, and Echo Wind LLC, has been executed by Kevin
Simmons, Senior Business Development Manager for Shell Wind Energy Inc., in his
capacity as President of the LLCs for each of the aforementioned projects.
3. On November 5, 2010, Idaho Power filed a Joint Petition and Motion
seeking a reduction in the published avoided cost rate eligibilty cap from 10 aMW to
100 kilowatts ("kW"). Case No. GNR-E-10-04. On December 3,2010, the Commission
APPLICATION - 2
issued Order No. 32131 setting a Modified Procedure comment schedule with which to
develop a record for its decision regarding the Joint Petition and Motion's request to
lower the published avoided cost rate eligibility cap. Comments are due on December
22, 2010, Reply Comments are due January 19, 2011, and Oral Argument is scheduled
for January 27, 2011. The Commission also ordered that its decision regarding whether
to reduce the published avoided cost eligibilty cap become effective on December 14,
2010.
4. Idaho Power has an obligation under federal law, FERC regulations, and
this Commission's Orders, that it has not been relieved of, to enter into power purchase
agreements with PURPA OFs. As stated in the Joint Petition filng, Idaho Power has
received a large amount, in terms of both volume and MWs, of requests from PURPA
OF developers demanding to enter into published avoided cost rate FESAs. The
Company continues to process these requests, in the ordinary course of business, and
file the same for review with this Commission, as is its legal obligation. However, the
request in this Application, as well as several other Applications that have been and wil
be filed over the course of the next couple of months, is made with the specific
reservation of rights and incorporation of the averments set forth in the Joint Petition
regarding the possible negative effects to the both the utilty and its customers of
additional and unfettered PURPA OF generation on system reliabilty, utilty operations,
and costs of incorporating and integrating such a large penetration level of PURPA OF
generation into the utilty's system.
5. As recently as November 2, 2010, in the Yellowstone Power case, the
Commission reiterated to Idaho Power that, "we intend for the Company to assist the
APPLICATION - 3
Commission in its gatekeeper role of assuring that utility customers are not being asked
to pay more than the Company's avoided cost for the OF contracts. We expect Idaho
Power to rigorously review such contracts." Order No. 32104. Even though Idaho
Power is legally obligated to continue to negotiate, execute, and submit PURPA OF
contracts for Commission review, it also feels obligated to reiterate that the continuing
and unchecked requirement for the Company to acquire additional intermittent and
other OF generation regardless of its need for additional energy or capacity on its
system not only circumvents the Integrated Resource Planning process and creates
system reliability and operational issues, but it also increases the price its customers
must pay for their energy needs.
II. THE FIRM ENERGY SALES AGREEMENT
6. On December 15, 2010, Idaho Power and Bravo entered into a FESA
pursuant to the terms and conditions of the various Commission Orders applicable to
this PURPA agreement for a wind resource. See Order Nos. 30415, 30488, 30738, and
31025. A copy of the FESA is attached to this Application as Attachment NO.1. Under
the terms of this FESA, Bravo elected to contract with Idaho Power for a 20-year term
using the non-Ievelized published avoided cost rates as currently established by the
Commission for energy deliveries of less than 10 average megawatts ("aMW"). This
FESA was executed by Bravo on December 13, 2010. It was subsequently executed by
Idaho Power on December 15, 2010, and now filed for the Commission's review on
December 16,2010.
7. The nameplate rating of this Facilty is 29.9 MW. As defined in paragraph
1.17 and paragraph 4.1.3 of the FESA, Bravo wil be required to provide data on the
APPLICATION - 4
Facilty that Idaho Power wil use to confirm that under normal and/or average
conditions, the Facilty wil not exceed 10 aMW on a monthly basis. Furthermore, as
described in paragraph 7.5 of the FESA, should the Facilty exceed 10 aMW on a
monthly basis, Idaho Power wil accept the energy (Inadvertent Energy) that does not
exceed the Maximum Capacity Amount, but wil not purchase or pay for this Inadvertent
Energy.
8. This PURPA wind agreement includes the Mechanical Availabilty
Guarantee ("MAG"), Wind Integration Cost reduction, and Wind Forecasting cost
sharing as required in Commission Order No. 30488. In addition, Bravo and Idaho
Power have agreed to Delay Liquidated Damages and associated Delay Security
provisions of $45 per kW of nameplate capacity within this FESA that have previously
been approved as reasonable by the Commission in several PURPA FESAs. See Case
Nos. IPC-E-10-02, IPC-E-10-05, IPC-E-10-15, IPC-E-10-16, IPC-E-10-17, IPC-E-10-18,
IPC-E-10-19, and IPC-E-10-22.
9. Bravo has elected October 31, 2014, as the Scheduled First Energy Date
and December 31, 2014, as the Scheduled Operation Date for this Facilty. See
Appendix B. Various requirements have been placed upon Bravo in order for Idaho
Power to accept energy deliveries from this Facilty. Idaho Power will monitor
compliance with these initial requirements. In addition, Idaho Power wil monitor the
ongoing requirements through the full term of this FESA.
10. The FESA, as signed and submitted by the parties thereto, contains non-
levelized published avoided cost rates in conformity with applicable IPUC Orders. All
APPLICATION - 5
applicable interconnection charges and monthly operation and maintenance charges
under Schedule 72 wil be assessed to Bravo.
11 . The FESA provides that all applicable interconnection charges and
monthly operational or maintenance charges under Schedule 72 wil be assessed to
Seller. The Facilty is currently in the beginning stages of the generator interconnection
process. Assuming that Seller continues to provide necessary technical information and
make payments for interconnection materials and studies in a timely manner, Idaho
Powets Delivery business unit wil be able to proceed with its interconnection and
transmission study processes, which ultimately results in a Schedule 72 Generator
Interconnection Agreement, or "GIA" between Bravo and Idaho Power. PURPA OF
generation must be designated as a network resource ("DNR") on Idaho Powets
system, which requires Idaho Power - Power Supply to submit a Transmission Service
Request ("TSR") on behalf of the Facilty to Idaho Power Delivery. Upon resolution of
any and all upgrades required to acquire transmission capacity for this Facility's
generation, and upon execution of the FESA and the GIA, this Facilty may then be
designated as a network resource.
12. Seller has selected October 31, 2014, for the Scheduled First Energy Date
and December 31, 2014, as the Scheduled Operation Date. Bravo has been advised
that it is Bravo's responsibilty to work with Idaho Powets Delivery business unit to
ensure that sufficient time and resources wil be available for Delivery to construct the
interconnection facilties, and transmission upgrades if required, in time to allow the
Facilty to achieve the December 31, 2014, Scheduled Operation date. Seller has been
further advised that delays in the interconnection or transmission process do not
APPLICATION - 6
constitute excusable delays in achieving the Scheduled Operation date and if Seller fails
to achieve the Scheduled Operation date at the times specified in the FESA, delay
damages wil be assessed. The developer of the Facilty has advised Idaho Power that
it is aware of these requirements and the accompanying risk inherent in demanding to
proceed with obligating itself to a Scheduled First Energy Date and Scheduled
Operation Date in the FESA without knowing what upgrades wil be required, and what
time frame the interconnection and potential system network upgrades can be
constructed within. Bravo has advised Idaho Power that is has been advised of and is
willng to take the responsibilty and risk associated with electing to proceed with this
contract without knowledge of the requirements of interconnection and possible
transmission upgrades.
13. Bravo has also been made aware of and accepted the provisions of the
FESA and the Company's approved Tariff Schedule 72 regarding non-compensated
curtailment or disconnection of its Facilty should certain operating conditions develop
on the Company's system. According to the standard provisions in Article XII of the
FESA, curtailment without compensation may occur if there is an event of Force
Majeure, a Forced Outage, or a temporary disconnection of the Facilty in accordance
with Tariff Schedule 72. If the generation from the Facilty wil have an adverse effect
upon Idaho Powets service to its customers, Idaho Power may temporarily disconnect
the Facilty from Idaho Powets transmission/distribution system as specified within
Schedule 72, or take such other reasonable steps as Idaho Power deems appropriate.
The parties' intent and understanding is that non-compensated curtailment would be
exercised when the generation being provided by the Facility in certain operating
APPLICATION - 7
conditions exceeds or approaches the minimum load levels of the Company's system
such that it may have a detrimental effect upon the Company's abilty to manage its
thermal, hydro, and other resources in order to meet its obligation to reliably serve loads
on its system.
14. Section 21 of the FESA provides that the FESA wil not become effective
until the Commission has approved all of the FESA's terms and conditions and declared
that all payments Idaho Power makes to Bravo for purchases of energy wil be allowed
as prudently incurred expenses for ratemaking purposes.
II. MODIFIED PROCEDURE
15. Idaho Power believes that a hearing is not necessary to consider the
issues presented herein and respectfully requests that this Application be processed
under Modified Procedure, Le., by written submissions rather than by hearing. RP 201
et seq. If, however, the Commission determines that a technical hearing is required, the
Company stands ready to prepare and present its testimony in such hearing.
IV. COMMUNICATIONS AND SERVICE OF PLEADINGS
16. Communications and service of pleadings, exhibits, orders, and other
documents relating to this proceeding should be sent to the following:
Donovan E. Walker, Senior Counsel
Lisa Nordstrom, Lead Counsel
Idaho Power Company
1221 West Idaho Street
P.O. Box 70
Boise, Idaho 83707
dwalker((idahopower.com
Inordstromayidahopower.com
Randy C. Allphin
Energy Contract Administrator
Idaho Power Company
1221 West Idaho Street
P.O. Box 70
Boise, Idaho 83707
rallphin((idahopower.com
APPLICATION - 8
V. REQUEST FOR RELIEF
17. Idaho Power Company respectfully requests that the Commission issue
an Order: (1) authorizing that this matter may be processed by Modified Procedure; (2)
accepting or rejecting the Firm Energy Sales Agreement between Idaho Power
Company and Bravo Wind LLC without change or condition; and, if accepted, (3)
declaring that all payments for purchases of energy under the Firm Energy Sales
Agreement between Idaho Power Company and Bravo Wind LLC be allowed as
prudently incurred expenses for rate making purposes.
Respectfully submitted this 16th day of December 2010.
etW~Kft~
Attorney for Idaho Power Company
APPLICATION - 9
CERTIFICATE OF MAILING
I HEREBY CERTIFY that on the 16th day of December 2010 I served a true and
correct copy of the within and foregoing APPLICATION upon the following named
parties by the method indicated below, and addressed to the following:
Bravo Wind LLC
Attn: Operations Manager
Bravo Wind LLC
c/o Cotterel Wind Energy Center LLC
150 North Dairy Ashford
Building C, Suite 356D
Houston, Texas 77079
Hand Delivered
-. U.S. Mail
_ Overnight Mail
FAX
-. Email dick.willams((shell.com
&9:c(~
Donovan E. Walker
APPLICATION - 10
BEFORE THE
IDAHO PUBLIC UTiliTIES COMMISSION
CASE NO. IPC-E-10-52
IDAHO POWER COMPANY
ATTACHMENT NO.1
Aricle
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
27
28
29
FIR ENERGY SALES AGREEMENT
BETWEEN
IDAHO POWER COMPANY
AN
BRAVO WIN LLC
TABLE OF CONTENTS
TITLE
Defintions
No Reliance on Idao Power
Warties
Conditions to Acceptance of Energy
Term and Operation Date
Puchase and Sale of Net Energy
Purchase Price and Method of Payment
Envionmental Attrbutes
Facilty and Interconnection
Metering and Telemetry
Records
Operations
Indemnification and Insurce
Force Majeure
Liabilty; Dedication
Several Obligations
Waiver
Choice of Laws and Venue
Disputes and Default
Governental Authorization
Commission Order
Successors and Assigns
Modification
Taxes
Notices
Additional Terms and Conditions
Severability
Counterpars
Entire Agreement Signatures
Appendix A
AppendixB
AppendixC
AppendixD
AppendixE
12/10/2010
FIR ENERGY SALES AGREEMENT
(10 aMW or Less)
Project Name: Bravo Wind Project
Project Number: 41455350
THIS AGREEMENT, entered into on this L day of December, 2010 between
BRAVO WIN LLC (Seller), and IDAHO POWER COMPAN, an Idaho corporation (Idaho Power),
hereinafter sometimes referred to collectively as "Paries" or individually as "Par."
WITNSSETH:
WHEREAS, Seller wil design, construct, own, maintain and operate an electric generation
facility; and
WHEREAS, Seller wishes to sell, and Idaho Power is wiling to purchase, firm electrc energy
produced by the Seller's Facilty.
THEREFORE, In considertion of the mutual covenants and agreements hereinafter set forth, the
Parties agree as follows:
ARTICLE I: DEFINITIONS
As used in this Agreement and the appendices attached hereto, the following terms
shall have the following meanings:
1.1 "Availabilty Shortfall Price" - The curent month's Mid-Columbia Market Energy Cost minus
the curent month's All Hours Energy Price specified in pargraph 7.3 of this Agreement. If this
calculation results in a value less than 15.00 Mils/kWh the result shall be 15.00 Mils/kWh.
1.2 "Business Days" - means any calendar day that is not a Saturday, a Sunday, or a NERC
recognized holiday.
1.3 "Calculated Net Energy Amount" - A monthly estimate, prepared and documented after the fact
by Seller, reviewed and accepted by the Buyer that is the calculated monthly maximum energy
1
12/10/2010
deliveries (measured in kWh) for each individual wind turbine, totaled for the Facility to
determine the total energy that the Facility could have delivered to Idaho Power during that
month based upon: (1) each wind tubines Nameplate Capacity, (2) Suffcient Pre Mover
available for use by each wind tubine during the month, (3) incidents of Force Majeure, (4)
scheduled maintenance, or (5) incidents of Forced Outages less Losses and Station Use. If the
durtion of an event characterized as item 3, 4 or 5 above (measured on each individual
occurence and individual wind tubine) lasts for less than 15 minutes, then the event wil not be
considered in this calculation. The Seller shall collect and maintain actual data to support this
calculation and shall keep this data for a minimum of 3 years.
1.4 "Commission" - The Idao Public Utilties Commission.
1.5 "Contract Year" - The period commencing each calendar year on the same calenda date as the
Operation Date and ending 364 days thereafter.
1.6 "Delay Liquidated Damages" - Damages payable to Idaho Power as calculated in paragraph 5.3,
5.4, 5.5 and 5.6.
1.7 "Delay Period" - All days past the Scheduled Operation Date until the Seller's Facility achieves
the Operation Date.
1.8 "Delay Price" - The current month's Mid-Columbia Market Energy Cost minus the curent
month's All Hours Energy Price specified in paragraph 7.3 of this Agreement. If this calculation
results in a value less than 0, the result of this calculation wil be O.
1.9 "Designated Dispatch Facility" - Idaho Power's Systems Operations Group, or any subsequent
group designated by Idao Power.
1.10 "Effective Date" - The date stated in the opening paragraph of this Fir Energy Sales
Agreement representing the date upon which this Fir Energy Sales Agreement was fully
executed by both Paries.
1.11 "Facility" - That electrc generation facilty described in Appendix B of this Agreement.
-2-
12/10/2010
1.12 "First Energy Date" - The day commencing at 00:01 hours, Mountain Time, following the day
that Seller has satisfied the requirements of Aricle IV and the Seller begins delivering energy to
the Idao Power electrical system at the Point of Delivery.
1.13 "Forced Outage" - a partial or total reduction of a) the Facility's capacity to produce and/or
deliver Net Energy to the Point of Delivery, or b) Idaho Power's abilty to accept Net Energy at
the Point of Delivery for non-economic reasons, as a result ofIdao Power or Facilty: 1)
equipment failure which was not the result of negligence or lack of preventative maintenance, or
2) responding to a transmission provider curilment order, or 3) unplaned preventative
maintenance to repair equipment that left unepaired, would result in failure of equipment prior
to the planned maintenance period, or 4) planed maintenance or construction of the Facilty or
electrical lines required to serve this Facility. The Paries shall make commercially reasonable
efforts to perform this unplanned preventative maintenance during periods of low wind
availabilty.
1.14 "Heayy Load Hours" - The daily hours beginning at 7:00 am, ending at 11:00 pm Mountain
Time, (16 hours) excluding all hours on all Sundays, New Years Day, Memorial Day,
Independence Day, Labor Day, Thanksgiving and Chrstmas.
1.15 "Inadvertent Energy" - Electric energy Seller does not intend to generate. Inadvertent energy is
more paricularly described in paragrph 7.5 of this Agreement.
1.16 "Interconnection Facilities" - All equipment specified in Idaho Power's Schedule 72.
1.17 "Intial Capacity Determination" - The process by which Idaho Power confirs that under
normal or average design conditions the Facility will generate at no more than 10 average MW
per month and is therefore eligible to be paid the published rates in accordance with Commssion
Order No. 29632.
1.18 "Light Load Hours" - The daily hours beginning at 11 :00 pm, ending at 7:00 am Mountain Time
(8 hours), plus all other hours on all Sundays, New Years Day, Memorial Day, Independence
Day, Labor Day, Thansgiving and Chrstmas.
-3-
12/10/2010
1.19 "Losses" - The loss of electrical energy expressed in kilowatt hours (kWh) occurrng as a result
of the transformation and transmission of energy between the Meterig Point and the point the
Facilty's energy is delivered to the Idaho Power electrical system. The loss calculation formula
wil be as specified in Appendix B of this Agreement.
1.20 "Market Energy Reference Price" - Eighty-five percent (85%) of the Mid-Columbia Market
Energy Cost.
1.21 "Material Breach" - A Default (paragraph 19.2.1) subject to paragraph 19.2.2.
1.22 "Maxium Capacity Amount" - The maximum capacity (MW) ofthe Facilty wil be as
specified in Appendix B of this Agreement.
1.23 "Mechanical Availabilty" - The percentage amount calculated by Seller within 5 days after the
end of each month of the Facilty's monthly actual Net Energy divided by the Facility's
Calculated Net Energy Amount for the applicable month. Any damages due as a result of the
Seller fallng short of the Mechanical Availabilty Guarantee for each month shall be determined
in accordance with paragraph 6.4.4.
1.24 "Mechanical Availabilty Guarantee" shall be as defined in paragrph 6.4.
1.25 "Metenng Equipment" - All equipment specified in Schedule 72, this Agreement and any
additional equipment specifed in Appendix B required to measure, record and telemeter bi-
directional power flows from the Seller's Facilty at the Meterng Point.
1.26 "Metenng Point" - The physical point at which the Metering Equipment is located that enables
accurate measurement of the Test Energy and Net Energy deliveries to Idaho Power at the Point
of Delivery for this Facility that provides all necessar data to administer this Agreement.
1.27 "Mid- Columbia Market Energy Cost" - The monthly weighted average of the daly on-peak and
off-peak Dow Jones Mid-Columbia Index (Dow Jones Mid-C Index) prices for non-firm energy.
If the Dow Jones Mid-Columbia Index price is discontinued by the reporting agency, both Parties
wil mutually agree upon a replacement index, which is similar to the Dow Jones Mid-Columbia
-4-
12/10/2010
Index. The selected replacement index wil be consistent with other similar agreements and a
commonly used index by the electrical industry.
1.28 "Nameplate Capacity" -The full-load electrical quantities assigned by the designer to a generator
and its prime mover or other piece of electrical equipment, such as transformers and circuit
breakers, ~nder standardized conditions, expressed in amperes, kilovolt-amperes, kilowatts, volts
or other appropriate unts. Usually indicated on a nameplate attached to the individual machine
or device.
1.29 "Net Energy" - All of the electric energy produced by the Facilty, less Station Use, less Losses,
expressed in kilowatt hours (kWh) delivered to Idao Power at the Point of Delivery. Subject to
the terms of this Agreement, Seller commits to deliver all Net Energy to Idao Power at the Point
of Delivery for the full term of the Agreement. Net Energy does not include Inadvertent Energy.
1.30 "Operation Date" - The day commencing at 00:01 hours, Mountain Time, following the day that
all requirements of paragraph 5.2 have been completed.
1.31 "Point of Delivery" - The location specified in Appendix B, where Idaho Power's and the
Seller's electrical facilities are interconnected and the energy from this Facilty is delivered to the
Idaho Power electrical system.
1.32 "Prudent Electrical Practices" - Those practices, methods and equipment that are commonly and
ordinaly used in electrical engineering and operations to operate electric equipment lawfully,
safely, dependably, efficiently and economically.
1.33 "Scheduled Operation Date" - The date specified in Appendix B when Seller anticipates
achievig the Operation Date. It is expected that the Scheduled Operation Date provided by the
Seller shall be a reasonable estimate of the date that the Seller anticipates that the Seller's Facilty
shall achieve the Operation Date.
1.34 "Schedule 72" - Idaho Power's Tariff No 101, Schedule 72 or its successor schedules as
approved by the Commission. The Seller shall be responsible to pay all costs of interconnection
-5-
12/10/2010
and integration of this Facility into the Idaho Power electrical system as specified within
Schedule 72 and this Agreement.
1.35 "Season" - The three perods identified in paragraph 6.2.1 of this Agreement.
1.36 "Special Facilities" - Additions or alterations of transmission and/or distribution lines and
transformers as described in Schedule 72.
1.37 "Station Use" - Electrc energy that is used to operate equipment that is auxilar or otherwise
related to the production of electricity by the Facility.
1.38 "Sufficient Prime Mover'~ means wind speed that is (1) equal to or greater than the generation
unit's manufactuer-specified minium levels required for the generation unt to produce energy,
and (2) equal to or less than the generation unit's manufacturer-specified maximum levels at
which the generation unit can safely produce energy.
1.39 "Surlus Energy" - All Net Energy produced by the Seller's Facility and delivered by the Facility
to the Idaho Power electrcal system prior to the Operation Date.
1.40 "Total Cost of the Facility" - The total cost of strctures, equipment and appurenances.
1.41 "Wind Energy Production Forecast" - A forecast of energy deliveries from this Facilty provided
by an Idaho Power administered wind forecasting modeL. The Facility shall be responsible for an
allocated portion of the total costs of the forecasting model as specified in Appendix E.
ARTICLE II: NO RELIANCE ON IDAHO POWER
2.1 Seller Independent Investigation - Seller warants and represents to Idaho Power that in enterig
into this Agreement and the undertakng by Seller of the obligations set forth herein, Seller has
investigated and determined that it is capable of performing hereunder and has not relied upon
the advice, experience or expertise of Idaho Power in connection with the transactions
contemplated by this Agreement.
2.2 Seller Independent Experts - All professionals or experts including, but not limited to, engineers,
attorneys, or accountants that Seller may have consulted or relied on in undertaking the
transactions contemplated by this Agreement have been solely those of Seller.
-6-
12/10/2010
ARTICLE II: WARTIES
3.1 No Warranty by Idaho Power - Any review, acceptance or failure to review Seller's design,
specifications, equipment or facilities shall not be an endorsement or a confiration by Idao
Power and Idao Power makes no warrnties, expressed or implied, regarding any aspect of
Seller's design, specifications, equipment or facilties, including, but not limited to, safety,
durabilty, reliability, strength, capacity, adequacy or economic feasibilty.
3.2 Qualifyng Facilty Status - Seller warants that the Facility is a "Qualifying Facility," as that term
is used and defined in 18 CFR 292.201 et seq. Afer initial qualification, Seller wil take such
steps as may be required to maintain the Facilty's Qualifying Facility status durng the ter of
this Agreement and Seller's failure to maintain Qualifyng Facility status wil be a Material
Breach of this Agreement. Idaho Power reserves the right to review the Facilty's Qualifyng
Facilty status and associated support and compliance documents at anytime durng the term of
this Agreement.
ARTICLE N: CONDITIONS TO ACCEPTANCE OF ENERGY
4.1 Prior to the First Energy Date and as a condition of Idaho Power's acceptance of deliveries of
energy from the Seller under this Agreement, Seller shall:
4.1.1 Submit proof to Idaho Power that all licenses, permits or approvals nece~sar for Seller's
operations have been obtained from applicable federal, state or local authorities,
including, but not limited to, evidence of compliance with Subpar B, 18 CFR 292.201 et
seq. as a certified Qualifyng Facility.
4.1.2 Opinion of Counsel - Submit to Idaho Power an Opinion Letter signed by an attorney
admitted to practice and in good standing in the State of Idaho providing an opinon that
Seller's licenses, perts and approvals as set forth in paragraph 4.1.1 above are legally
and validly issued, are held in the name of the Seller and, based on a reasonable
independent review, counsel is of the opinion that Seller is in substantial compliance with
-7-
12/10/2010
said permits as of the date of the Opinion Letter. The Opinion Letter wil be in a form
acceptable to Idaho Power and wil acknowledge that the attorney rendering the opinion
understands that Idaho Power is relying on said opinon. Idaho Power's acceptace of the
form wil not be uneasonably withheld. The Opinion Letter wil be governed by and
shall be interpreted in accordance with the legal opinion accord of the American Bar
Association Section of Business Law (1991).
4.1.3 Initial Capacity Determination - Submit to Idao Power such data as Idao Power may
reasonably require to perform the Intial Capacity Determination. Such data wil include
but not be limited to, Nameplate Capacity, equipment specifications, prime mover data,
resource characterstics, normal and/or average operating design conditions and Station
Use data. Upon receipt of this information, Idaho Power wil review the provided data
and if necessar, request additional data to complete the Initial Capacity Determation
within a reasonable time.
4.1.3.1 If the Maximum Capacity specified in Appendix B of this Agreement and the
cumulative manufacture Nameplate Capacity rating of the individual generation
units at this Facility is less than 10 MW, the Seller shall submit detailed,
manufacturer, verifiable data of the Nameplate Capacity ratings of the actual
individual generation units to be installed at this Facility. Upon verification by
Idao Power that the data provided establishes the combined Nameplate Capacity
rating ofthe generation units to be installed at this Facility is less than 10 MW, it
wil be deemed that the Seller has satisfied the Initial Capacity Determation for
this Facility.
4.1.4 Nameplate Capacity - Submit to Idaho Power manufacturer's and engineering
documentation that establishes the Nameplate Capacity of each individual generation unit
that is included within this entire Facility. Upon receipt of this data, Idaho Power shall
review the provided data and determine if the Nameplate Capacity specified is reasonable
-8-
12/10/2010
based upon the manufacturer's specified generation ratings for the specific generation
units.
4.1.5 Engineer's Certifications - Submit an executed Engieer's Certification of Design &
Construction Adequacy and an Engineer's Certification of Operations and Maintenance
(O&M) Policy as described in Commission Order No. 21690. These certificates wil be
in the form specified in Appendix C but may be modified to the extent necessar to
recognize the different engineering disciplines providing the certificates.
4.1.6 Insurance - Submit written proof to Idaho Power of all insurance required in Aricle XII.
4.1.7 Interconnection - Provide written confirmation from Idaho Power's delivery business
unit that Seller has satisfied all interconnection requirements.
4.1.8 Network Resource Designation - The Seller's Facility has been designated as a network
resource capable of deliverig firm energy up to the amount of the Maximum Capacity.
4.1.8.1 Seller has provided all information required to enable Idaho Power to file an
initial trasmission capacity request.
a) Results of the intial transmission capacity request are known and acceptable
to the Seller.
b) Seller acknowledges responsibility for all interconnection costs and any costs
associated with acquirg adequate firm transmission capacity to enable the
project to be classified as an Idaho Power designated firm network resource.
c.) If the Facility is located outside of the Idao Power service terrtory, in
addition to the above requirements, the Seller must provide evidence that the
Seller has acquired firm transmission capacity from all required transmitting
entities to deliver the Facility's energy to an acceptable point of delivery on
the Idao Power electrcal system.
4.1.9 Written Acceptance - Request and obtain written confirmation from Idaho Power that all
conditions to acceptance of energy have been fulfilled. Such written confiration shall be
-9-
12/10/2010
provided within a commercially reasonable time following the Seller's request and wil
not be unreasonably withheld by Idao Power.
ARTICLE V: TERM AN OPERATION DATE
5.1 Ter - Subject to the provisions of paragraph 5.2 below, this Agreement shall become effective
on the date first written and shall continue in full force and effect for a period of twenty (20)
Contract Years from the Operation Date.
5.2 Operation Date - The Operation Date may occur only after the Facilty has achieved all of the
following:
a) Achieved the First Energy Date.
b) Commssion approval of this Agreement in a form acceptable to Idaho Power has
been received.
c) Seller has demonstrated to Idao Power's satisfaction that the Facility is complete and
able to provide energy in a consistent, reliable and safe maner.
d) Seller has requested an Operation Date from Idaho Power in a written format.
e) Seller has received written confiration from Idaho Power of the Operation Date.
Ths confirmation wil not be uneasonably withheld by Idaho Power.
5.3 Operation Date Delay - Seller shall cause the Facility to achieve the Operation Date on or before
the Scheduled Operation Date. Delays in the interconnection and transmission network upgrade
study, design and construction process that are not Force Majeure events accepted by both
Paries, shall not prevent Delay Liquidated Damages from being due and owing as calculated in
accordance with this Agreement.
5.3.1 If the Operation Date occur after the Scheduled Operation Date but on or prior to ninety
(90) days following the Scheduled Operation Date, Seller shall pay Idao Power Delay
Liquidated Damages calculated at the end of each calendar month after the Scheduled
Operation Date as follows:
Delay Liquidated Damages are equal to ((Curent month's Initial Year Net
-10-
12/10/2010
Energy Amount as specified in paragraph 6.2.1 divided by the number of days in
the curent month) multiplied by the number of days in the Delay Period in the
curent month) multiplied by the current month's Delay Price.
5.3.2 If the Operation Date does not occur withi niety (90) days following the Scheduled
Operation Date, the Seller shall pay Idaho Power Delay Liquidated Damages, in addition
to those provided in paragraph 5.3.1, calculated as follows:
Forty five-dollar ($45) multiplied by the Maximum Capacity with the Maximum
Capacity being measured in kW.
5.4 If Seller fails to achieve the Operation Date within ninety (90) days following the Scheduled
Operation Date, such failure wil be a Material Breach and Idao Power may terminate this
Agreement at any time until the Seller cures the Material Breach. Additional Delay Liquidated
Damages beyond those calculated in 5.3.1 and 5.3.2 wil be calculated and payable using the
Delay Liquidated Damage calculation described in 5.3.1 above for all days exceeding ninety (90)
days past the Scheduled Operation Date until such time as the Seller cures this Material Breach or
Idaho Power terminates this Agreement.
5.5 Seller shall pay Idaho Power any calculated Delay Liquidated Damages within seven (7) days of
when Idaho Power calculates and presents any Delay Liquidated Damages bilings to the Seller.
Seller's failure to pay these damages within the specified time wil be a Material Breach of this
Agreement and Idao Power shall draw fuds frm the Delay Securty provided by the Seller in
an amount equal to the calculated Delay Liquidated Damages.
5.6 The Paries agree that the damages Idao Power would incur due to delay in the Facility
achieving the Operation Date on or before the Scheduled Operation Date would be difficult or
impossible to predict with certainty, and that the Delay Liquidated Damages are an appropriate
approximation of such damages.
5.7 Prior to the Seller executing this Agreement, the Seller shall have agreed to and executed a Letter
of Understanding with Idaho Power that contains at a minium the following requirements:
-11-
12/10/2010
a) Seller has filed for interconnection and is in compliance with all payments
and requirements of the interconnection process.
b) Seller has provided all information required to enable Idaho Power to file an
initial transmission capacity request.
5.8 Within thiry (30) days of the date of a final non-appealable Commission Order as specified in
Aricle XXI approving this Agreement; Seller shall post liquid securty ("Delay Securty") in a
form as described in Appendix D equal to or exceeding the amount calculated in paragraph 5.8.1.
Failure to post this Delay Security in the time specified above wil be a Material Breach of this
Agreement and Idaho Power may terminate this Agreement.
5.8.1 Delay Securty The greater of forty-five dollars ($45) multiplied by the Maximum
Capacity with the Maximum Capacity being measured in kW or the sum of thee month's
estimated revenue. Where the estimated three months of revenue is the estimated revenue
associated with the first three full months following the estimated Scheduled Operation
Date, the estimated kWh of energy production as specified in paragraph 6.2.1 for those
three months multiplied by the All Hours Energy Price specified in paragraph 7.3 for
each of those three months.
5.8.1.1 In the event (a) Seller provides Idaho Power with certification that (1) a
generation interconnection agreement specifyng a schedule that wil enable this
Facility to achieve the Operation Date no later than the Scheduled Operation
Date has been completed and the Seller has paid all required interconnection
costs, or (2) a generation interconnection agreement is substantially complete and
all material costs of interconnection have been identified and agreed upon and
the Seller is in compliance with all terms and conditions of the generation
interconnection agreement, the Delay Security calculated in accordance with
paragraph 5.8.1 wil be reduced by ten percent (10%).
-12-
12/10/2010
5.8.1.2 If the Seller has received a reduction in the calculated Delay Securty as specified
in paragraph 5.8.1.1 and subsequently (1) at Seller's request, the generation
interconnection agreement specified in paragraph 5.8.1.1 is revised and as a
result the Facility wil not achieve its Operation Date by the Scheduled Operation
Date, or (2) if the Seller does not maintain compliance with the generation
interconnection agreement, the full amount of the Delay Securty as calculated in
paragraph 5.8.1 wil be subject to reinstatement and will be due and owing within
five (5) business days from the date Idao Power requests reinstatement. Failure
to timely reinstate the Delay Securty wil be a Material Breach of this
Agreement.
5.8.2 Idaho Power shall release any remaining securty posted hereunder after all
calculated Delay Liquidated Damages are paid in full to Idaho Power and the
earlier of: 1) thiry (30) days after the Operation Date has been achieved, or 2)
sixty (60) days after the Agreement has been terminated.
ARTICLE VI: PURCHASE AN SALE OF NET ENERGY
6.1 Delivery and Acceptance of Net Energy - Except when either Pary's performance is excused as
provided herein, Idaho Power will purchase and Seller wil sell all of the Net Energy to Idaho
Power at the Point of Delivery. All Inadvertent Energy produced by the Facility wil also be
delivered by the Seller to Idaho Power at the Point of Delivery. At no time wil the total amount
of Net Energy and/or Inadvertent Energy produced by the Facilty and delivered by the Seller to
the Point of Delivery exceed the Maximum Capacity Amount.
6.2 Net Energy Amounts - Seller intends to produce and deliver Net Energy in the following montWy
amounts. These amounts shall be consistent with the Mechanical Availabilty Guarantee.
-13-
12/10/2010
6.2.1 Initial Year Monthly Net Energy Amounts:
Month
Season 1
March
April
May
Season 2
July
August
November
December
Season 3
June
September
October
Januar
Februar
kWh
7,068,000
6,498,000
6,704,066
4,750,101
5,087,837
6,477,481
7,068,000
6,286,024
5,228,259
6,713,545
6,768,876
6,384,000
6.3 Unless excused by an event of Force Majeure, Seller's failure to deliver Net Energy in any
Contract Year in an amount equal to at least ten percent (10%) of the sum of the Intial Year
Monthly Net Energy Amounts as specified in pargraph 6.2 shall constitute an event of default.
6.4 Mechanical Availability Guarantee - Afer the Operational Date has been established, the Facilty
shall achieve a minimum monthly Mechancal Availability of eighty-five percent (85%) for the
Facilty for each month during the full term of this Agreement (the "Mechanical Availabilty
Guarantee"). Failure to achieve the Mechanical Availabilty Guarantee shall result in Idaho
Power calculating damages as specified in paragraph 6.4.4.
6.4.1 At the same time the Seller provides the Monthly Power Production and Availabilty
Report (Appendix A), the Seller shall provide and certify the calculation of the Facilty's
current month's Mechanical Availability. The Seller shall include a summar of all
information used to calculate the Calculated Net Energy Amount including but not
limited to: (a) Forced Outages, (b) Force Majeure events, (c) wind speeds and the impact
on generation output, and (c) scheduled maintenance and Station Use information.
6.4.2 The Seller shall maintain and retain for thee (3) years detailed documentation supporting
-14-
the monthly calculation of the Facilty's Mechanical Availabilty.
12/10/2010
6.4.3 Idaho Power shall have the right to review and audit the documentation supporting the
calculation of the Facility's Mechancal Availability at reasonable times at the Seller's
offces.
6.4.4 If the curent month's Mechanical Availabilty is less than the Mechanical Availability
Guarantee, damages shall be equal to:
((eighty-five (85) percent of the month's Calculated Net Energy Amount)
minus the month's actual Net Energy deliveries) multiplied by the
Availability Shortfall Price.
6.4.5 Any damages calculated in paragraph 6.4.4 wil be offset against the curent month's
energy payment. If an unpaid balance remains after the daages are offset against the
energy payment, the Seller shall pay in full the remaining balance within thirty (30) days
of the date of the invoice.
ARTICLE VII: PURCHASE PRICE AND METHOD OF PAYMENT
7.1 Heavv Load Purchase Price - For all Net Energy received durng Heavy Load Hour,
Idaho Power wil pay the non-levelized energy price in accordance with Commission Order
31025 adjusted in accordance with Commission Order 30415 for Heavy Load Hour Energy
deliveries, adjusted in accordance with Commssion Order 30488 for the wind integration charge,
and with seasonalization factors applied:
Yeår
Season 1 - (73.50 %)
Mils/kWh
Season 2 - (120.00 %)
Mills/kWh
Season 3 - (100.00 %)
Mils/kWh
2010
2011
2012
2013
2014
2015
2016
2017
2018
2019
40.52
42.80
45.32
47.71
50.29
53.05
54.64
56.20
57.90
59.57
66.15
69.87
74.00
78.18
82.74
87.64
90.46
93.23
96.25
99.21
55.12
58.24
61.66
64.92
68.42
72.17
74.34
76.61
79.12
81.59
-15-
12/10/2010
2020 61.29 102.27 84.14
2021 63.33 105.90 87.16
2022 65.46 109.67 90.31
2023 67.67 113.59 93.57
2024 69.97 117.66 96.97
2025 72.35 121.90 100.50
2026 74.38 125.49 103.49
2027 76.62 129.20 106.58
2028 78.96 133.03 109.77
2029 81.38 136.97 113.06
2030 83.87 141.04 116.45
2031 87.22 146.51 121.01
2032 90.15 151.30 125.00
2033 93.19 156.26 129.13
7.2 Light Load Puchase Price - For all Net Energy received during Light Load Hours, Idao Power
wil pay the non-levelized energy price in accordance with Commission Order 31025 adjusted in
accordance with Commission Order 30415 for Light Load Hour Energy deliveries, adjusted in
accordance with Commission Order 30488 for the wind integration charge, and with
seasonalization factors applied:
Season 1 - (73.50 %)Season 2 - (120.00 %)Season 3 - (100.00 %)
Year Mils/kWh Mils/kWh Mils/kWh
2010 35.59 58.11 48.42
2011 37.88 61.84 51.54
2012 40.40 65.95 54.96
2013 42.79 69.86 58.22
2014 45.37 74.06 61.72
2015 48.13 78.91 65.48
2016 49.72 81.73 67.64
2017 51.28 84.50 69.76
2018 52.97 87.51 72.07
2019 54.65 90.47 74.35
2020 56.37 93.53 76.86
2021 58.41 97.16 79.88
2022 60.54 100.93 83.03
2023 62.74 104.85 86.29
2024 65.04 108.92 89.69
2025 67.43 113.16 93.22
2026 69.45 116.76 96.21
2027 71.55 120.47 99.30
-16-
12/10/2010
2028 73.70 124.29 102.49
2029 76.03 128.24 105.78
2030 78.52 132.31 109.1 7
2031 81.87 137.77 113.73
2032 84.80 142.56 117.72
2033 87.84 147.52 121.85
7.3 All Hour Energy Price - The price to be used in the calculation of the Surplus Energy Price and
Delay Price shall be the non-levelized energy price in accordance with Commission Order 31025
adjusted in accordance with Commission Order 30488 for the wind integration charge,and with
seasonalization factors applied:
Season 1 - (73.50 %)Season 2 - (120.00 %)Season 3 - (100.00 %)
Year MilslkWh MilslkWh MilslkWh
2010 38.33 62.57 52.14
2011 40.61 66.30 55.26
2012 43.13 70.42 58.68
2013 45.52 74.33 61.93
2014 48.10 78.85 65.44
2015 50.86 83.75 69.19
2016 52.45 86.58 71.36
2017 54.01 89.35 73.48
2018 55.71 92.36 75.88
2019 57.37 95.32 78.35
2020 59.10 98.38 80.90
2021 61.14 102.01 83.92
2022 63.27 105.78 87.07
2023 65.48 109.70 90.33
2024 67.78 113.77 93.73
2025 70.16 118.01 97.26
2026 72.18 121.60 100.25
2027 74.28 125.31 103.35
2028 76.58 129.14 106.53
2029 79.00 133.09 109.82
2030 81.49 137.16 113.21
2031 84.84 142.62 117.77
2032 87.77 147.41 121.76
2033 90.81 152.37 125.89
7.4 Surplus Energy Price - For all Surplus Energy, Idaho Power shall pay to the Seller the curent
month's Market Energy Reference Price or the All Hours Energy Price specified in paragraph
-17-
12/1012010
7.3, whichever is lower.
7.5 Inadvertent Energy -
7.5.1 Inadvertent Energy is electric energy produced by the Facility, expressed in kWh,
which the Seller delivers to Idao Power at the Point of Delivery that exceeds 10,000
kW multiplied by the hours in the specific month in which the energy was delivered.
(For example Januar contains 744 hours. 744 hours times 10,000 kW = 7,440,000
kWh. Energy delivered in Januar in excess of 7,440, 000 kWh in this example
would be Inadvertent Energy.)
7.5.2 Although Seller intends to design and operate the Facility to generate no more than
ten (10) average MW and therefore does not intend to generate Inadvertent Energy,
Idaho Power wil accept Inadvertent Energy that does not exceed the Maximum
Capacity Amount but wil not purchase or pay for Inadvertent Energy.
7.6 Payment Due Date - Undisputed Energy payments, less the Wind Energy Production Forecasting
Monthly Cost Allocation (MCA) described in Appendix E and any other payments due Idaho
Power, wil be disbured to the Seller within 30 days of the date whích Idaho Power receives and
accepts the documentation of the monthly Mechanical Available Guartee and the Net Energy
actually delivered to Idaho Power as specified in Appendix A.
7.7 Continuing Jursdiction of the Commission _ Ths Agreement is a special contract and, as such, the
rates, terms and conditions contained in this Agreement wil be construed in accordace with
Idao Power Company v. Idaho Public Utilties Commssion and Afton Energy, Inc., 107 Idaho
781, 693 P.2d 427 (1984), Idao Power Company v. Idaho Public Utilities Commission, 107
Idaho 1122,695 P.2d i 261 (1985), Afon Energy, Inc, v. Idaho Power Company, 111 Idaho 925,
729 P.2d 400 (1986), Section 210 of the Public Utility Regulatory Policies Act of 1978 and 18
CFR §292.303-308.
-18-
12/1012010
ARTICLE VII: ENVIRONMENTAL ATTRIUTES
8.1 Seller retains ownership under this Agreement of green tags and renewable energy certificates
(RECs), or the equivalent environmental attributes, directly associated with the production of
energy from the Seller's Facility sold to Idaho Power.
ARTICLE IX: FACILITY AN INERCONNCTION
9.1 Design of Facility - Seller wil design, construct, install, own, operate and maintain the Facility
and any Seller-owned Interconnection Facilities so as to allow safe and reliable generation and
delivery of Net Energy and Inadvertent Energy to the Idaho Power Point of Delivery for the full
term of the Agreement.
9.2 Interconnection Facilities - Except as specifically provided for in this Agreement, the required
Interconnection Facilties wil be in accordace with Schedule 72, the Generation Interconnection
Process and Appendix B. The Seller is responsible for all costs associated with this equipment as
specified in Schedule 72 and the Generation Interconnection Process, includig but not limited to
initial costs incurred by Idaho Power for equipment costs, installation costs and ongoing monthly
Idao Power operations and maintenance expenses.
ARTICLE X: METERIG AND TELEMETRY -
10.1 Metering - Idaho Power shall, for the account of Seller, provide, install, and maintain Meterg
and Telemetry Equipment to be located at a mutually agreed upon location to record and measure
power flows to Idaho Power in accordance with this Agreement and Schedule 72. The Metering
Equipment wil be at the location and the type required to measure, record and report the
Facilty's Net Energy, Station Use, Inadvertent Energy and maximum energy deliveries (kW) at
the Point of Delivery in a maner to provide Idaho Power adequate energy measurement data to
administer this Agreement and to integrate this Facility's energy production into the Idaho Power
electrical system.
10.2 Telemetry - Idaho Power wil install, operate and maintain at Seller's expense metering,
-19-
12/10/2010
communications and telemetry equipment which wil be capable of providing Idaho Power with
continuous instantaneous telemetry of Seller's Net Energy and Inadvertent Energy produced and
delivered to the Idaho Power Point of Delivery to Idaho Power's Designated Dispatch Facility.
ARTICLE XI - RECORDS
11.1 Maintenance of Records - Seller shall maintain at the Facilty or such other location mutually
acceptable to the Parties adequate total generation, Net Energy, Station Use, Inadvertent Energy
and maximum generation (kW) records in a form and content acceptable to Idaho Power.
11.2 Inspection - Either Party, after reasonable notice to the other Pary, shall have the right, durg
normal business hours, to inspect and audit any or all generation, Net Energy, Station Use,
Inadvertent Energy and maximum generation (kW) records pertaining to the Seller's Facility.
ARTICLE XII: OPERATIONS
12.1 Communications - Idaho Power and the Seller shall maintain appropriate operating
communications through Idao Power's Designated Dispatch Facilty in accordace with
Appendix A of this Agreement.
12 .2 Energy Acceptance -
12.2.1 Idaho Power shall be excused from accepting and payig for Net Energy or accepting
Inadvertent Energy which would have otherwise been produced by the Facility and
delivered by the Seller to the Point of Delivery, if it is prevented from doing so by an
event of Force Majeure, Forced Outage or temporar disconnection of the Facility in
accordance with Schedule 72. If, for reasons other than an event of Force Majeure or a
Forced Outage, a temporar disconnection under Schedule 72 exceeds twenty (20) days,
beginning with the twenty-first day of such interrption, curailment or reduction, Seller
wil be deemed to be delivering Net Energy at a rate equivalent to the pro rata daily
average of the amounts specified for the applicable month in paragraph 6.2. Idaho Power
wil notify Seller when the interrption, curtailment or reduction is terminated.
-20-
12/10/2010
12.2.2 If, in the reasonable opinon of Idaho Power, Seller's operation of the Facilty or
Interconnection Facilities is unsafe or may otherwise adversely affect Idaho Power's
equipment, personnel or service to its customers, Idaho Power may temporarly
disconnect the Facility from Idaho Power's transmission/distribution system as specified
within Schedule 72 or take such other reasonable steps as Idao Power deems
appropriate.
12.2.3 Under no circumstances wil the Seller deliver Net Energy and/or Inadvertent Energy
from the Facility to the Point of Delivery in an amount that exceeds the Maximum
Capacity Amount at any moment in time. Seller's failure to limit deliveries to the
Maximum Capacity Amount wil be a Material Breach of this Agreement.
12.2.4 IfIdaho Power is unable to accept the energy from this Facility and is not excused from
accepting the Facility's energy, Idao Power's damages shall be limited to only the value
of the estimated energy that Idaho Power was unable to accept. Idaho Power wil have
no responsibilty to pay for any other costs, lost revenue or consequential damages the
Facilty may incur.
12.3 Scheduled Maintenance - On or before January 31st of each calendar year, Seller shall submit a
written proposed maintenance schedule of significant Facility maintenance for that calenda year
and Idaho Power and Seller shall mutually agree as to the acceptability of the proposed schedule.
The Paries determination as to the acceptabilty of the Seller's timetable for scheduled
maintenance wil take into consideration Prudent Electrical Practices, Idao Power system
requirements and the Seller's preferred schedule. Neither Pary shall uneasonably withhold
acceptance of the proposed maintenance schedule.
12.4 Maintenance Coordination - The Seller and Idao Power shall, to the extent practical, coordinate
their respective line and Facility maintenance schedules such that they occur simultaneously.
12.5 Contact Prior to Curailment - Idaho Power wil make a reasonable attempt to contact the Seller
prior to exercising its rights to interrpt interconnection or curail deliveries from the Seller's
-21-
12/10/2010
Facilty. Seller understands that in the case of emergency circumstances, real time operations of
the electrical system, and/or unplanned events Idao Power may not be able to provide notice to
the Seller prior to interrption, curtailment, or reduction of electrical energy deliveries to
Idaho Power.
ARTICLE XII: INEMNFICATION AN INSURCE
13.1 Indemnfication - Each Pary shall agree to hold harless and to indemnify the other Pary, its
offcers, agents, affliates, subsidiares, parent company and employees against all loss, daage,
expense and liability to third persons for injur to or death of person or injury to property,
proximately caused by the indemnifying Party's (a) construction, ownership, operation or
maintenance of, or by failure of, any of such Pary's works or facilties used in connection with
this Agreement, or (b) negligent or intentional acts, errors or omissions. The indemnifying Pary
shall, on the other Pary's request, defend any suit asserting a claim covered by this indemnity.
The indemnifyng Pary shall pay all documented costs, including reasonable attorney fees that
may be incured by the other Party in enforcing this indemnty.
13.2 Insurance - During the term of this Agreement, Seller shall secure and continuously car the
following insurance coverage:
13.2.1 Comprehensive General Liability Insurance for both bodily injur and property daage
with limits equal to $1,000,000, each occurrence, combined single limit. The deductible
for such insurance shall be consistent with curent Insurance Industry Utility practices for
similar property.
13.2.2 The above insurance coverage shall be placed with an insurance company with an A.M.
Best Company rating of A- or better and shall include:
(a) An endorsement naming Idaho Power as an additional insured and loss payee as
applicable; and
(b) A provision stating that such policy shall not be canceled or the limits of liabilty
reduced without sixty (60) days' prior wrtten notice to Idao Power.
-22-
12/10/2010
13.3 Seller to Provide Certificate of Insurance - As required in paragraph 4.1.6 herein and annually
thereafter, Seller shall fuish Idao Power a certificate of insurance, together with the
endorsements required therein, evidencing the coverage as set forth above.
13.4 Seller to Notify Idao Power of Loss of Coverage - If the insurce coverage required by
paragrph 13.2 shall lapse for any reason, Seller wil immediately notify Idaho Power in writing.
The notice wil advise Idaho Power of the specific reason for the lapse and the steps Seller is
taking to reinstate the coverage. Failure to provide this notice and to expeditiously reinstate or
replace the coverage wil constitute a Materal Breach of this Agreement.
ARTICLE XIV: FORCE MAJEUR
14.1 As used in this Agreement, "Force Majeure" or "an event of Force Majeure" means any cause
beyond the control of the Seller or of Idaho Power which, despite the exercise of due diligence,
such Pary is unable to prevent or overcome. Force Majeure includes, but is not limited to, acts of
God, fire, flood, storms, wars, hostilties, civil strife, strikes and other labor distubances,
earhquakes, fires, lightning, epidemics, sabotage, or changes in law or regulation occurng after
the Effective Date, which, by the exercise of reasonable foresight such pary could not reasonably
have been expected to avoid and by the exercise of due diligence, it shall be unable to overcome.
If either Pary is rendered wholly or in par unable to perorm its obligations under this
Agreement because of an event of Force Majeure, both Paries shall be excused from whatever
performance is affected by the event of Force Majeure, provided that:
(l) The non-performng Party shall, as soon as is reasonably possible after the
occurrence of the Force Majeure, give the other Pary written notice describing
the pariculars of the occurence.
(2) The suspension of performance shall be of no greater scope and of no longer
duration than is required by the event of Force Majeure.
(3) No obligations of either Party which arose before the occurence causing the
suspension of performance and which could and should have been fully
-23-
12/10/2010
performed before such occurrence shall be excused as a result of such
occurence.
ARTICLE XV: LIAILITY; DEDICATION
15.1 Limitation of Liabilty. Nothing in this Agreement shall be construed to create any duty to, any
standad of care with reference to, or any liabilty to any person not a Pary to this Agreement.
Neither pary shall be liable to the other for any indirect, special, consequential, nor puntive
damages, except as expressly authorized by this Agreement.
15.2 Dedication. No undertakig by one Party to the other under any provision of this Agreement
shall constitute the dedication of that Pary's system or any portion thereof to the Party or the
public or affect the status of Idaho Power as an independent public utilty corporation or Seller as
an independent individual or entity.
ARTICLE XVI: SEVERA OBLIGATIONS
16.1 Except where specifically stated in this Agreement to be otherwise, the duties, obligations and
liabilties of the Parties are intended to be several and not joint or collective. Nothing contained
in this Agreement shall ever be construed to create an association, trust, parnership or joint
venture or impose a trust or partnership duty, obligation or liabilty on or with regard to either
Pary. Each Pary shall be individually and severally liable for its own obligations under this
Agreement.
ARTICLE XVII: WAIER
17.1 Any waiver at any time by either Pary of its rights with respect to a default under this Agreement
or with respect to any other matters arsing in connection with this Agreement shall not be
deemed a waiver with respect to any subsequent default or other matter.
-24-
12/10/2010
ARTICLE XVII: CHOICE OF LAWS AN VENU
18.1 This Agreement shall be construed and interpreted in accordance with the laws of the State of
Idaho without reference to its choice of law provisions.
18.2 Venue for any litigation arsing out of or related to this Agreement wil lie in the District Cour of
the Fourh Judicial District ofIdao in and for the County of Ada.
ARTICLE XIX: DISPUTES AN DEFAULT
19.1 Disputes - All disputes related to or arising under this Agreement, including, but not limited to,
the interpretation of the terms and conditions of this Agreement, wil be submitted to the
Commission for resolution.
19.2 Notice of Default
19.2.1 Defaults. If either Pary fails to perform any of the terms or conditions of this
Agreement (an "event of default"), the non-defaulting Party shall cause notice in
writing to be given to the defaulting Pary, specifying the maner in which such
default occurred. If the defaulting Pary shall fail to cure such default within the sixty
(60) days after service of such notice, or if the defaulting Party reasonably
demonstrates to the other Party that the default can be cured within a commercially
reasonable time but not within such sixty (60) day perod and then fails to dilgently
pursue such cure, then, the non-defaulting Party may, at its option, terminate this
Agreement and/or pursue its legal or equitable remedies.
19.2.2 Material Breaches - The notice and cure provisions in paragraph 19.2.1 do not apply
to defaults identified in this Agreement as Material Breaches. Material Breaches must
be cured as expeditiously as possible following occurrence of the breach.
19.3 Security for Performance - Prior to the Operation Date and thereafter for the full term of this
Agreement, Seller wil provide Idaho Power with the following:
19.3.1 Insurance - Evidence of compliance with the provisions of paragraph 13.2. If Seller
-25-
12/10/2010
19.3.2
19.3.3
fails to comply, such failure wil be a Material Breach and may only be cured by
Seller supplyig evidence that the required insurance coverage has been replaced or
reinstated;
Engineer's Certifications - Every three (3) years after the Operation Date, Seller wil
supply Idaho Power with a Certification of Ongoing Operations and Maintenance
(O&M) from a Registered Professional Engineer licensed in the State of Idaho, which
Certification of Ongoing 0 & M shall be in the form specified in Appendix C. Seller's
failure to supply the required certificate wil be an event of default. Such a default
may only be cured by Seller providig the required certificate; and
Licenses and Permits - During the full term of this Agreement, Seller shall maintain
compliance with all permts and licenses described in paragraph 4.1.1 of this
Agreement. In addition, Seller wil supply Idaho Power with copies of any new or
additional permts or licenses. At least every fifth Contract Year, Seller wil update the
documentation described in Paragraph 4.1.1. If at any time Seller fails to maintain
compliance with the permits and licenses described in paragraph 4.1.1 or to provide
the documentation required by this paragraph, such failure wil be an event of default
and may only be cured by Seller submitting to Idao Power evidence of compliance
from the permitting agency.
ARTICLE XX: GOVERNENTAL AUTHORIATION
20.1 This Agreement is subject to the jursdiction of those governental agencies having control over
either Pary of this Agreement.
ARTICLE XXI: COMMISSION ORDER
21.1 This Agreement shall become finally effective upon the Commission's approval of all terms and
provisions hereof without change or condition and declaration that all payments to be made to
Seller hereunder shall be allowed as prudently incured expenses for ratemakg purposes.
-26-
12/10/2010
ARTICLE XXII: SUCCESSORS AN ASSIGNS
22.1 This Agreement and all of the terms and provisions hereof shall be binding upon and inure to the
benefit of the respective successors and assigns of the Parties hereto, except that no assignent
hereof by either Pary shall become effective without the written consent of both Parties being
first obtained. Such consent shall not be uneasonably withheld. Notwithstanding the foregoing,
any pary which Idaho Power may consolidate, or into which it may merge, or to which it may
conveyor transfer substantially all of its electric utility assets, shall automatically, without fuher
act, and without need of consent or approval by the Seller, succeed to all of Idaho Power's rights,
obligations and interests under this Agreement. This article shall not prevent a financing entity
with recorded or secured rights from exercising all rights and remedies available to it under law
or contract. Idaho Power shall have the right to be notified by the finncing entity that it is
exercising such rights or remedies.
ARTICLE XXII: MODIFICATION
23.1 No modification to this Agreement shall be valid unless it is in wrting and signed by both Paries
and subsequently approved by the Commssion.
ARTICLE XXIV: TAXES
24.1 Each Pary shall pay before delinquency all taxes and other governental charges which, if failed
to be paid when due, could result in a lien upon the Facility or the Interconnection Facilties.
ARTICLE XXV: NOTICES
25.1 All written notices under this Agreement shall be directed as follows and shall be considered
delivered when faxed, e-mailed and confirmed with deposit in the U.S. Mail, first-class, postage
prepaid, as follows:
-27-
12/10/2010
To Seller:
Original document to:
Bravo Wind LLC
Attention: Operations Manager
C/O Cotterel WindEnergy Center LLC
150 N. Dair Ashford,
Building C, Suite 356D
Houston, TX 77079
Phone: 832-337-2555
E-mail: dick.wiliams~shel1.com
To Idaho Power:
Original document to:
Senior Vice President, Power Supply
Idaho Power Company
P.O. Box 70
Boise, Idaho 83707
Email: Lgrow~idahopower.com
Copy of document to:
Cogeneration and Small Power Production
Idaho Power Company
P.O. Box 70
Boise, Idao 83707
E-mail: rallphitfidaopower.com
Either Party may change the contact person and/or address information listed above, by providing written
notice from an authorized person representing the Party.
ARTICLE XXVI: ADDITIONAL TERMS AN CONDITIONS
26.1 This Agreement includes the following appendices, which are attached hereto and included by
reference:
Appendix A
AppendixB
AppendixC
AppendixD
AppendixE
Monthly Power Production and Availability Report
Facility and Point of Delivery
Engineer's Cerifications
Forms of Liquid Securty
Wind Energy Production Forecasting
-28-
12/10/2010
ARTICLE XXVII: SEVERAILITY
27.1 The invalidity or unenforceability of any term or provision of this Agreement shall not affect the
validity or enforceabilty of any other terms or provisions and this Agreement shall be constred
in all other respects as if the invalid or unenforceable term or provision were omitted.
ARTICLE XXVil: COUNERPARTS
28.1 This Agreement may be executed in two or more counterparts, each of which shall be deemed an
original but all of which together shall constitute one and the same instruent.
ARTICLE XXIX: ENTIR AGREEMENT
29.1 This Agreement constitutes the entire Agreement of the Paries concerning the subject matter
hereof and supersedes all prior or contemporaneous oral or wrtten agreements between the
Paries concernng the subject matter hereof.
IN WITNESS WHEREOF, The Parties hereto have caused this Agreement to be executed
in their respective names on the dates set fort below:
Idaho Power Company Bravo Wind LLC
By fill a bTLisa A Grow
Sr. Vice President, Power Supply
By
Dick Wiliams
President
Dated J¿. 16, i()Dated 1-i1J(~
"Idaho Power""Seller"
-29-
12/10/2010
APPENDIX A
A-I MONTHLY POWER PRODUCTION AN AVAIABILITY REPORT
At the end of each month the following required documentation wil be submitted to:
Idaho Power Company
Attn: Cogeneration and Small Power Production
P.O. Box 70
Boise, Idaho 83707
The meter readings required on this report wil be the readings on the Idaho Power Meter Equipment
measurig the Facility's total energy production delivered to Idaho Power and Station Usage and the
maximum generated energy (kW) as recorded on the Meterng Equipment and/or any other required
energy measurements to adequately administer this Agreement. Ths document shall be the document to
enable Idaho Power to begin the energy payment calculation and payment process. The meter readings
on this report shall not be used to calculate the actul payment, but instead wil be a check of the
automated meter reading information that wil be gathered as described in item A-2 below:
This report shall also include the Seller's calculation of the Mechanical Availability.
-30-
12/10/2010
Idaho Power Company
Cogeneration and Small Power Production
MONTHLY POWER PRODUCTION AND AVAIABILITY REPORT
Month Year
Project Name Project Number:
Address Phone Number:
City State Zip
Net Facilty
Output
Station
Usage
Station
Usage
Metered
Maximum Generation
Meter Number:
End of Month kWh Meter Reading:
Beginnng of Month kWh Meter:
Difference:
Times Meter Constant:
kW
Net Generation
kWh for the Month:
Metered Demand:
Mechanical Availabilty Guarantee
Seller Calculated Mechanical Availabilty
As specified in this Agreement, the Seller shall include with this monthly report a summary statement of the
Mechanical Availabilty of this Facilty for the calendar month. This summary shall include details as to how
the Seller calculated this value and summary of the Facilty data used in the calculation. Idaho Power and
the Seller shall work together to mutually develop a summary report that provides the required data. Idaho
Power reserves the right to review the detailed data used in this calculation as allowed within the Agreement.
DateSignature
-31-
12/10/2010
A-2 AUTOMATED METER READING COLLECTION PROCESS
Monthly, Idaho Power wil use the provided Metering and Telemetry equipment and processes to collect
the meter reading information from the Idaho Power provided Metering Equipment that measures the Net
Energy and energy delivered to supply Station Use for the Facility recorded at 12:00 AM (Midnght) of
the last day of the month.
The meter information collected wil include but not be limited to energy production, Station Use, the
maximum generation (kW) and any other required energy measurements to adequately admnister this
Agreement.
A-3 ROUTIN REPORTING
Idaho Power Contact Information
Daily Energy Production Reporting
Call daily by 10 a.m., 1-800-356-4328 or 1-800-635-1093 and leave the following
information:
. Project Identification - Project Name and Project Number
. Current Meter Reading
. Estimated Genertion for the curent day
. Estimated Generation for the next day
Planned and Unplaned Project outages
Call 1-800-345-1319 and leave the following information:
. Project Identification - Project Name and Project Number
. Approximate time outage occured
Estimated day and time of project coming back online
Seller's Contact Information
24-Hour Project Operational Contact
Name:
Telephone Number:
Cell Phone:
-32-
12/10/2010
Project On-site Contact information
Telephone Number:
-33-
12/10/2010
APPENDIXB
FACILITY AN POIN OF DELIVERY
Project Name: Bravo Wind Project
Project Number: 41455350
B-1 DESCRITION OF FACILITY
(Must include the Nameplate Capacity rating and V AR capabilty (both leading and lagging) of all
generation units to be included in the Facility.)
The Facilty wil consist of 13 Siemens wind tubines with individual generator nameplate ratings
of 2.3 MW for each unit, for a total Facilty generator nameplate rating of 29.9 MW, with a
maximum Facility output of 29.9 MW. Each generating unit has a reactive power capabilty
(V AR capabilty) of 1,114 kVA delivered (lagging) to 1, 114 kVA consumed (leading). Seller
and Idaho Power may mutually agree to substitution, any time prior to the Operation Date, a
different manufacturer and/or model wind turbine provided that the aggregate nameplate rating of
the Facility does not exceed 30 MW.
If the Seller wishes to substitute different wind turbines, the Seller shall provide detailed
specifications of the proposed substitute wind turbines to Idaho Power. Idaho Power wil then
review this detailed information and either accept or reject the Seller's proposed substitute wind
turbines. Idaho Power's acceptance of the substitute wind tubines wil be required by both
confirmations that the interconnection is able to accommodate the substitute wind turbines and
that the substitute wind turbines are acceptable under this Agreement. Only after Idao Power's
acceptance of the substitute wind tubines shall the Seller be allowed to install the substitute wind
turbines, which acceptance shall not be uneasonably withheld.
-34-
1211012010
B-2 LOCATION OF FACILITY
Near: Burley, il
SEC 13 & 24, TIl S, R25E, County: Cassia, il
SEC 7, 8 & 19, TIl S, R26E, County: Cassia, il
Description of Interconnection Location: On-site in SEC 25, TIl S, R25E, Elmore County, Id.
Interconnect with an existing Idaho Power 138 kV distribution line. Exact point of
interconnection to be determed as par of the Idaho Power delivery business unt's
interconnection study process.
Nearest Idaho Power Substation: Minidoka Substation
B-3 SCHEDULED FIRST ENERGY AN OPERATION DATE
Seller has selected October 31, 2014 as the Scheduled First Energy Date.
Seller has selected December 31, 2014 as the Scheduled Operation Date.
In making these selections, Seller recognizes that adequate testing of the Facility and completion
of all requirements in paragraph 5.2 of this Agreement must be completed prior to the project
being granted an Operation Date.
B-4 MAXIMUM CAPACITY AMOUN:
This value wil be 29.9 MW which is consistent with the value provided by the Seller to
Idao Power in accordace with Schedule 72. This value is the maximum energy (MW) that
potentially could be delivered by the Seller's Facility to the Idaho Power electrical system at any
moment in time.
B-5 POIN OF DELIVERY
"Point of Delivery" means, unless otherwise agreed by both Paries, the point of where the Sellers
Facility's energy is delivered to the Idao Power electrical system. Schedule 72 wil determine
the specific Point of Delivery for this Facility. The Point of Delivery identified by Schedule 72
wil become an integral par of this Agreement.
-35-
12/10/2010
B-6 LOSSES
If the Idaho Power Metering equipment is capable of measurig the exact energy deliveries by the
Seller to the Idaho Power electrical system at the Point of Delivery, no Losses wil be calculated
for this Facilty. If the Idaho Power Meterng equipment is unable to measure the exact energy
deliveries by the Seller to the Idaho Power electrical system at the Point of Delivery, a Losses
calculation wil be established to measure the energy losses (kWh) between the Seller's Facility
and the Idaho Power Point of Delivery. This loss calculation wil be initially set at 2% of the
kWh energy production recorded on the Facilty generation meterig equipment. At such time as
Seller provides Idaho Power with the electrcal equipment specifications (transformer loss
specifications, conductor sizes, etc.) of all of the electrcal equipment between the Facility and the
Idaho Power electrical system, Idaho Power wil configure a revised loss calculation formula to
be agreed to by both paries and used to calculate the kWh Losses for the remaining term of the
Agreement. If at any time durig the term of this Agreement, Idao Power determines that the
loss calculation does not correctly reflect the actual kWh losses attributed to the electrical
equipment between the Facility and the Idaho Power electrical system, Idaho Power may adjust
the calculation and retroactively adjust the previous months kWh loss calculations.
B-7 METERIG AN TELEMETRY
Schedule 72 wil determine the specific meterig and telemetry requirements for this Facilty. At
the minimum, the Metering Equipment and Telemetry equipment must be able to provide and
record hourly energy deliveries to the Point of Delivery and any other energy measurements
required to administer this Agreement. These specifications wil include but not be limited to
equipment specifications, equipment location, Idao Power provided equipment, Seller provided
equipment, and all costs associated with the equipment, design and installation of the
Idaho Power provided equipment. Seller wil arange for and make available at Seller's cost
communcation circuit(s) compatible with Idaho Power's communications equipment and
dedicated to Idao Power's use termnating at the Idaho Power facilities capable of providing
-36-
12/10/2010
Idaho Power with continuous instantaneous information on the Facilities energy production.
Idaho Power provided equipment wil be owned and maintained by Idaho Power, with total cost
of purchase, installation, operation, and maintenance, including administrative cost to be
reimbursed to Idaho Power by the Seller. Payment of these costs wil be in accordance with
Schedule 72 and the total metering cost wil be included in the calculation of the Monthly
Operation and Maintenance Charges specified in Schedule 72.
B-8 NETWORK RESOURCE DESIGNATION
Idaho Power canot accept or pay for generation from this Facilty until a Network Resource
Designation ("NR") application has been accepted by Idaho Power's delivery business unt.
Federal Energy Regulatory Commssion ("FERC") rules require Idaho Power to prepare and
submit the NR. Because much of the information Idao Power needs to prepare the NR is
specific to the Seller's Facility, Idaho Power's abilty to fie the NR in a timely maner is
contingent upon timely receipt of the required information from the Seller. Prior to Idaho Power
beginning the process to enable Idao Power to submit a request for NR status for this Facility,
the Seller shall have completed all requirements as specified in Paragraph 5.7 of this Agreement.
Seller's failure to provide complete and accurate information in a timely manner can
significantly impact Idaho Power's abilty and cost to attain the NRD designation for the
Seller's Facilty and the Seller shall bear the costs of any of these delays that are a result of
any action or inaction by the Seller.
-37-
12/10/2010
APPENDIXC
ENGINER'S CERTIFICATION
OF
OPERATIONS & MAIENANCE POLICY
The undersigned , on behalf of hiself/erself and
, hereinafter collectively referred to as "Engineer," hereby states and certifies to the Seller
as follows:
1. That Engineer is a Licensed Professional Engineer in good stading in the State of Idao.
2. That Engineer has reviewed the Energy Sales Agreement, hereinafter "Agreement," between
Idaho Power as Buyer, and as Seller, dated
3. That the cogeneration or small power production project which is the subject of the Agreement
and this Statement is identified as IPCo Facility No.and is hereinafter referred to as
the "Project."
4.That the Project, which is commonly known as the Project, is located in
Section _ Township Range , Boise Meridian,County, Idaho.
5. That Engineer recognizes that the Agreement provides for the Project to fush electrical energy
to Idaho Power for a 20 year period.
6. That Engineer has substantial expenence in the design, construction and operation of electric
power plants of the same type as this Project.
7. That Engineer has no economic relationship to the Design Engineer of this Project.
8. That Engineer has reviewed and/or supervsed the review of the Policy for Operation and
Maintenance ("O&M") for this Project and it is his professional opinion that, provided said Project has
been designed and built to appropriate standards, adherence to said O&M Policy wil result in the
Project's producing at or near the design electrical output, effciency and plant factor for a 20 year period.
-38-
12/10/2010
9. That Engineer recognizes that Idaho Power, in accordace with paragraph 5.2 of the Agreement,
is relying on Engineer's representations and opinons contained in this Statement.
10. That Engineer certifies that the above statements are complete, true and accurte to the best of
hisler knowledge and therefore sets his!her hand and seal below.
By
(P .E. Stamp)
Date
-39-
12/1012010
APPENDIXC
ENGINER'S CERTIFICATION
OF
ONGOING OPERATIONS AND MAIENANCE
The undersigned , on behalf of himselfherself
hereinafter collectively referred to as "Engineer," hereby states andand
certifies to the Seller as follows:
1. That Engineer is a Licensed Professional Engineer in good standig in the State of Idao.
2. That Engineer has reviewed the Energy Sales Agreement, hereinafter "Agreement," between
Idaho Power as Buyer, and as Seller, dated
3. That the cogeneration or small power production project which is the subject of the Agreement
and this Statement is identified as IPCo Facility No. and hereinafter refered to as the
"Project" .
4. That the Project, which is commonly known as the Project, is located in
Section _ Township Range , Boise Meridian, County, Idaho.
5. That Engineer recognizes that the Agreement provides for the Project to furnish electrical energy
to Idaho Power for a 20 year period.
6. That Engineer has substantial experience in the design, construction and operation of electrc
power plants of the same type as this Project.
7. That Engineer has no economic relationship to the Design Engineer of this Project.
-40-
12/10/2010
8. That Engineer has made a physical inspection of said Project, its operations and maintenance
records since the last previous certified inspection. It is Engineer's professional opinon, based on the
Project's appearance, that its ongoing O&M has been substantially in accordance with said O&M Policy;
that it is in reasonably good operating condition; and that if adherence to said O&M Policy continues, the
Project will continue producing at or near its design electrical output, effciency and plant factor for the
remaining years of the Agreement.
9. That Engineer recognizes that Idaho Power, in accordace with pargraph 5.2 of the Agreement,
is relying on Engineer's representations and opinions contained in this Statement.
10. That Engineer certifies that the above statements are complete, true and accurate to the best of
his/her knowledge and therefore sets his/her hand and seal below.
By
(P .E. Stamp)
Date
-41-
12/10/2010
APPENDIXC
ENGINER'S CERTIFICATION
OF
DESIGN & CONSTRUCTION ADEQUACY
The undersigned , on behalf of himselflherself and
hereinafter collectively referred to as "Engieer", hereby states and
certifies to Idaho Power as follows:
1.That Engineer is a Licensed Professional Engineer in good standing in the State of Idao.
2.That Engineer has reviewed the Fir Energy Sales Agreement, hereinafter "Agreement",
between Idaho Power as Buyer, and as Seller, dated ~
3.That the cogeneration or small power production project, which is the subject of the
Agreement and this Statement, is identified as IPCo Facility No and is hereinafter
referred to as the "Project".
4.That the Project, which is commonly known as the Project, is located in
Section Township" -Range , Boise Meridian,County, Idaho.
5.That Engineer recognizes that the Agreement provides for the Project to fuish electrical
energy to Idaho Power for a 20 year period.
6.That Engineer has substantial experience in the design, constrction and operation of
electric power plants of the same type as this Project.
7.That Engineer has no economic relationship to the Design Engineer of this Project and
has made the analysis of the plans and specifications independently.
8.That Engineer has reviewed the engineering design and construction of the Project,
including the civil work, electrical work, generating equipment, prime mover conveyance system, Seller
fuished Interconnection Facilities and other Project facilties and equipment.
-42-
12/10/2010
9. That the Project has been constructed in accordance with said plans and specifications, all
applicable codes and consistent with Prudent Electrical Practices as that term is described in the
Agreement.
10. That the design and construction of the Project is such that with reasonable and prudent
operation and maintenance practices by Seller, the Project is capable of performg in accordance with the
terms of the Agreement and with Prudent Electncal Practices for a 20 year period.
11.That Engineer recognizes that Idaho Power, in accordance with paragrph 5.2 of the
Agreement, in interconnecting the Project with its system, is relying on Engineer's representations and
opinions contained in this Statement.
12. That Engineer certifies that the above statements are complete, true and accurate to the
best of his/her knowledge and therefore sets hislher hand and seal below.
By
(P .E. Stamp)
Date
-43-
12/10/2010
APPENDIXD
FORMS OF LIQUI SECURY
The Seller shall provide Idaho Power with commercially reasonable securty instruents such as Cash
Escrow Securty, Guarantee or Letter of Credit as those terms are defined below or other forms ofliquid
financial security that would provide readily available cash to Idaho Power to satisfy the Delay Securty
requirement and any other security requirement within this Agreement.
For the purose ofthis Appendix D, the term "Credit Requirements" shall mean acceptable financial
creditworthiness of the entity providing the security instrument in relation to the term of the obligation in
the reasonable judgment ofIdaho Power, provided that any guarantee and/or letter of credit issued by any
other entity with a short-term or long-term investment grade credit rating by Standad & Poor's
Corporation or Moody's Investor Services, Inc. shall be deemed to have acceptable financial
creditworthiess.
1. Cash Escrow Securty - Seller shall deposit fuds in an escrow account established by the
Seller in a bankng institution acceptable to both Paries equal to the Delay Security or any
other required securty amount(s). The Seller shall be responsible for all costs, and receive
any interest earned associated with establishig and maintaining the escrow account(s).
Guarantee or Letter of Credit Securty - Seller shall post and maintain in an amount equal to the Delay
Security or other required securityamount(s): (a) a guaranty from a pary that satisfies the Credit
Requirements, in a form acceptable to Idaho Power at its discretion, or b) an irrevocable Letter of Credit
in a form acceptable to Idaho Power, in favor ofIdaho Power. The Letter of Credit wil be issued by a
financial institution acceptable to both paries. The Seller shall be responsible for all costs associated
with establishing and maintaining the Guarantee(s) or Letter(s) of Credit.
-44-
12/10/2010
APPENDIXE
WIN ENERGY PRODUCTION FORECASTING
As specified in Commission Order 30488, Idaho Power shall make use of a Wind Energy Production
Forecasting model to forecast the energy production from this Facility and other Qualifyng Facility wind
generation resources. Seller and Idaho Power wil share the cost of Wind Energy Production Forecasting.
The Facilty's share of Wind Energy Production Forecasting is determined as specified below. Sellers
share wil not be greater than 0.1 % of the total energy payments made to Seller by Idao Power durg the
previous Contract Year.
a. For every month of this Agreement beginnng with the first full month after the
First Energy Date as specified in Appendix of this Agreement, the Wind Energy
Production Forecasting Monthly Cost Allocation (MCA) wil be due and payable
by the Seller. Any Wind Energy Production Forecasting Monthly Cost
Allocations (MCA) that are not reimbursed to Idaho Power shall be deducted
from energy payments to the Seller.
b. As the value of the 0.1 % cap of the Facilties total energy payments wil not be
known until the first Contract Year is complete, at the end of the first Contract
Year any prior allocations that exceeded the 0.1 % cap shall be adjusted to reflect
the 0.1 % cap. If the Facility has paid the monthly allocations, a refund wil be
included in equal monthly amounts over the ensuing Contract Year. If the
Facilty has not paid the monthly allocations, the amount due to Idao Power wil
be adjusted accordingly and the unpaid balance wil be deducted from the
ensuing Contract Year's energy payments.
-45-
12/10/2010
c. The cost allocation formula described below wil be reviewed and revised if
necessar on the last day of any month in which the cumulative MW nameplate
rating of wind projects havig Commission approved agreements to deliver
energy to Idaho Power has been revised by an action of the Commssion.
d. The monthly cost allocation wil be based upon the following formula:
Where: Total MW (TMW is equal to the total nameplate rating of all QF wind
projects that are under contract to provide energy to Idaho Power
Company.
Facilty MW (¥ID is equal to the nameplate rating of this Facility as
specified in Appendix B.
Annual Wind Energy Production Forecasting Cost (AFCost) is equal
to the total anual cost Idaho Power incurs to provide Wind Energy
Production Forecasting. Idaho Power wil estimate the AFCost for the
current year based upon the previous year's cost and expected costs for
the current year. At year-end, Idaho Power wil compare the actual costs
to the estimated costs and any differences between the estimated AFCost
and the actual AFCost wil be included in the next year's AFCost.
Annual Cost Allocation (ACA) = AFCost X (FMW / TMW)
And
Monthly Cost Allocation (MCA) = ACA / 12
e. The Wind Energy Production Forecasting Monthly Cost Allocation (MCA) is
due and payable to Idaho Power. The MCA wil first be netted against any
monthly energy payments owed to the Seller. If the netting of the MCA against
the monthly energy payments results in a balance being due Idaho Power, the
Facility shall pay this amount within 15 days of the date of the payment invoice.
-46-
12/10/2010